Terms and Conditions – MCG General contractor LLC
Last Updated: February 18, 2025
1. Introduction
Welcome to MCG General contractor LLC. By using our services, you agree to the following terms and conditions. Please read them carefully before proceeding.
2. Services Provided
MCG General Contractor LLC specializes in general contracting services, including but not limited to:
Residential and commercial construction
Remodeling and renovations
Project management
Design-build services
3. Estimates and Proposals
All estimates provided are valid for 30 days from the date of issuance.
Estimates are based on the current scope of work and may be subject to change upon further inspection or unforeseen circumstances.
4. Contracts and Agreements
A detailed contract outlining the scope of work, payment schedule, and project timeline will be provided for all projects.
Work will commence upon receipt of a signed contract and any required deposits.
5. Client Responsibilities
Clients agree to:
Provide access to the property as needed for project completion.
Ensure all necessary permits and approvals are obtained unless otherwise agreed upon.
Communicate any changes or concerns promptly.
6. Payment Terms
Payment schedules will be outlined in the contract.
Accepted payment methods include credit cards, checks, and bank transfers.
Late payments may incur additional fees as specified in the contract.
7. Changes and Modifications
Any changes to the project scope must be documented in a written change order, which may affect the project cost and timeline.
Verbal agreements are not binding until documented in writing.
8. Project Timeline
Estimated start and completion dates will be provided in the contract.
MCG General Contractor LLC is not liable for delays caused by factors beyond our control, such as weather conditions, supply chain disruptions, or unforeseen site conditions.
9. Warranties and Guarantees
Workmanship is warranted for a period of one year from the date of project completion.
Manufacturer warranties apply to all materials used, and any claims will be processed in accordance with their terms.
10. Limitation of Liability
MCG General Contractor LLC is not liable for incidental, indirect, or consequential damages arising from the project.
Our total liability shall not exceed the total amount paid by the client for the services rendered.
11. Termination
Either party may terminate the contract with written notice under the terms specified in the contract.
Upon termination, the client is responsible for payment of all work completed up to the termination date.
12. Governing Law
These terms and conditions are governed by the laws of the State of Pennsylvania. Any disputes will be resolved in the courts of Pennsylvania.
13. Amendments
MCG General Contractor LLC reserves the right to amend these terms at any time. Clients will be notified of significant changes that may affect their agreements.
14. Contact Information
For questions or concerns, please contact us at
Phone: +1 (267) 369-5253
Email: [email protected]
Disclaimer: This site is not a part of Facebook™, Instagram™, or any other social media platform. Additionally, this site is NOT endorsed by Facebook™ or Instagram™ in any way. Facebook™ and Instagram™ are trademarks of their respective companies. All information provided is for informational purposes only. For full details, please refer to our Privacy Policy
